1. Introduction
These Terms & Conditions (“Terms”) govern your use of https://lealglassinc.com/ (the “Website”) and any services, quotes, communications, or transactions provided by LealGlass Inc (“Company,” “we,” “our,” or “us”).
By accessing our Website or submitting a request, you agree to be bound by these Terms. If you do not agree, you should not use this Website.
2. Nature of Our Business
LealGlass Inc provides glass shower doors, glass panels, and related products. We operate as a supplier/wholesale-focused business and may provide product information, pricing, and quotes upon request.
We do not guarantee availability of all products at all times.
3. Quotes & Pricing
All pricing provided on the Website or through direct communication is:
- Subject to confirmation
- May change without prior notice
- Based on project details provided by the customer
Final pricing is confirmed only through an official invoice or written confirmation from our team.
4. Orders
An order is considered confirmed only after:
- Written confirmation by LealGlass Inc, and
- Receipt of agreed payment (if applicable)
We reserve the right to refuse or cancel any order at our discretion.
5. Payments
We may require partial or full payment depending on order type.
Accepted payment methods will be communicated at the time of purchase or invoicing.
Failure to complete payment may result in order delays or cancellation.
6. Shipping & Delivery
Shipping timelines are estimates only and may vary due to:
- Product availability
- Carrier delays
- External logistical factors
LealGlass Inc is not responsible for delays caused by third-party carriers.
Risk of loss transfers to the customer upon delivery to the carrier or specified delivery address, depending on the shipping terms agreed
7. Installation
Unless explicitly stated in writing, LealGlass Inc does not provide installation services.
Customers are responsible for hiring qualified professionals for installation.
We are not liable for damages, improper installation, or issues resulting from third-party installation services.
8. Returns & Cancellations
Due to the custom or project-based nature of many products, returns or cancellations may be limited or not accepted once production or processing has begun.
Any return or cancellation requests must be submitted in writing and are subject to approval.
9. Product Information
We strive to ensure all product descriptions, measurements, and specifications are accurate. However:
- Minor variations may occur
- Images are for illustrative purposes only
- Customers are responsible for verifying project measurements before ordering
10. Warranty Disclaimer
Unless explicitly stated, products are provided without any additional warranties beyond those provided by manufacturers (if applicable).
LealGlass Inc does not guarantee installation results or compatibility with all project conditions.
11. Limitation of Liability
To the maximum extent permitted by law, LealGlass Inc shall not be liable for any:
- Indirect or consequential damages
- Loss of profits or revenue
- Installation errors
- Misuse or improper handling of products
Our total liability shall not exceed the amount paid for the product or service in question.
12. Intellectual Property
All content on this Website, including text, images, logos, and design elements, is the property of LealGlass Inc and may not be copied, reproduced, or used without permission.
13. Third-Party Services
We may use third-party services for payment processing, analytics, marketing, and website functionality. We are not responsible for the actions or policies of these third parties.
14. Privacy
Your use of the Website is also governed by our Privacy Policy and Cookie Policy.
15. Governing Law
These Terms are governed by and construed in accordance with the laws of the State of Florida, United States, without regard to conflict of law principles.
Any disputes shall be resolved in the courts located in Florida.
16. Changes to Terms
We may update these Terms at any time without prior notice. Continued use of the Website constitutes acceptance of the updated Terms.
17. Contact Information
If you have any questions about these Terms & Conditions, please contact us:
LealGlass Inc
Website: https://lealglassinc.com/
Email: sales@lealglassinc.com
Phone: +1 305-842-0305
